工厂建造合同 建造合同
导读:工作计划范文范文,工厂建造合同怎么写,格式要求,写法技巧,科教范文网展示的这篇文章是很好的参考:第一条 定义 业主指_________。 承包商指 第一条 定义 业主指_________。 承包商指_________。 工厂指在附录_________中指定的构成固定设备的全部机器、设备和材料。 工地指按本合同用于建造工厂的全部土地。 工程指承包商按本合同实施的工程。 合同价格指业主向承包商支付的全部工程款项。第二条 承包商的职责 1.承包商应负责设计、筹划以及在工地上建造工厂。 2.除了业主根据第_________条提供的项目和设施,承包商应提供所有为使工厂成功建造所必需的设备、材料、工具、设施、劳工和服务。 3.承包商应根据附录_________中的日程安排施工。 4.承包商应根据附录_________中的规定为业主培训工厂设备的操作和维修人员。 5.承包商应向业主提供附录_________中规定的备件。 6.承包商应向业主提供附录_________中指定的维修设备。第三条 业主的职责 1.业主应提供工地,并在本合同有效期内允许承包商自由地、不受干扰地出入该工地。 2.业主应按时提供附录_________中指定的物件和设施。 3.业主将从有关部门获取为工厂建造、设备运行所必需的执照和许可证,包括承包商雇员的工作许可证。 4.业主应按第_________条中规定的合同价格向承包商支付工程款项。第四条 合同价格 1.在本合同生效后_________天内,业主应向承包商支付金额为合同价格,作为承包商完成该工程并承担本合同规定的所有义务的全部报酬。 2.合同价格不再上调,完成工种的成本风险应由承包商承担,商定合同价格时应认为承包商已获得全部信息并已把所有可能影响成本的因素估计在内。 (科教范文网 lw.AsEac.com编辑整理) 第五条 设计图样 1.承包商应根据合同,在附录_________规定的时间内向业主提交工厂建造所需的图样,供业主审批。业主应在收到这些图样后一个月内,对图样进行审核,并作出批准或不批准的决定。 2.承包商应对上述图样中的任何缺点、错误或疏漏负责,除非这种缺点、错误或疏漏是因业主书面提供的不准确信息所致。 3.业主或承包商互相提供的所有图样和技术资料,收到方应作为机密文件对待,除非另有商定,收到方不得将这些图样和资料用于与本合同无关的其他目的。第六条 检验 1.承包商应该按法律和正常的工程惯例的要求,负责工厂所有的检验和试验工作。 2.业主有权在任何适当时间对建造中的工厂的材料和工艺进行检验和测试,费用自理。这种检验或测试不能免除承包商在合同中应尽的任何义务。 3.完工后的工厂应由业主进行检验和测试;工厂何时可以测试,承包商应提前以书面形式通知业主。 4.承包商应根据业主的合理要求,为彻底而有效的检测提供所需要的协助、劳力、材料、电力、燃料、设备、备用品和仪器。 5.工厂通过上述测试后,业主应向承包商签发一份表示通过测试的证书。检测中发现的任何问题未圆满解决,工厂不得移交。第七条 工地 1.承包商应在工地上提供所有令业主满意的材料、劳力、设备、服务和便利,以便顺利施工和完工。 2.在总体上得到上述保证的前提下,承包商应提供下列各项必需品: a.建筑设备; b.工地上使用的运输工具,包括临时道路; c.保护人员和财产安全所需的篱笆、灯光、岗哨以及所有其他材料和服务; (科教作文网 zw.nseac.com整理) d.为材料和施工人员(包括业主雇员)提供临时仓库、办公室和其他房屋建筑; e.在整个工程移交之前提供电话、灭火设备和急救设备; f.供施工人员使用的卫生设备和食堂。 3.承包商应遵守当地法律规定的所安全及其他条例。 4.无论何时,承包商都不应在业主的房产及其邻近建筑物、车道和街道上堆积施工用建筑材料和建筑垃圾,工程完工后,应从建筑物及其周围清除所有用剩的材料,保持工地和工厂安全、整洁,以备使用。第八条 承包商的工作人员 1.承包商将自费为其全部工作人员提供饮食、交通及一切必要的便利。 2.合同签署后,承包商应指定一名项目经理,在工程进行过程中全权代表承包商。他将在工作时间内坐镇施工现场。业主向项目经理发出的所有指示,如同发给承包商本人一样,同样具有约束力。 3.如果业主认为工地上承包商的雇员品行不端、不能胜任工作或有失职行为,可要求承包商将此人调离或更换。第九条 责任 1.在工厂被最终验收之前,承包商应对工厂的任何损失或损坏负责,并自费将其修复,直至业主满意。然而,如果根据本合同,这类损坏的责任不在承包商,而业主要求予以修复,承包商应按业主指示办理,但费用由业主负担。 2.在最后验收合格证书签发之前,凡因承包商或其分包商的疏忽,或设计、材料或工艺上的缺陷而产生的任何财产损失或人身伤害,承包商应向业主赔偿,并保护业主免受由此而产生的各种诉讼、索赔、要求或费用支出。 3.如果业主因某种原因遭受索赔或诉讼,而按本条款规定承包商应该或可能对该事由承担法律责任,则业主应立即书面通知承包商。承包商应以业主名义接手并通过谈判处理解决或能由此而产生的诉讼,并承担一切费用。如承包商要求,业主应向承包商提供承包商为处理此类索赔或诉讼所需要的所有资料和帮助。您可以访问中国科教评价网(www.NsEac.com)查看更多相关的文章。
第十条 保险 1.在不限制承包商责任的情况下,承包商将自费投保下列险: a.机器设备从工厂交货到目的地的运输险。 b.为承包商和分包商的所的雇员投保雇员赔偿险,或者根据适用的法律和法规投保类似的法定社会保险。 c.防备财产损坏或人身伤害的产品责任险,期限到维修期结束,每次事件的金额不少于_________美元。 d.对承包商或其分包商在执行本合同中使用的所有车辆投保综合汽车责任险。 2.上述保险单应以承包商及其分包商、业主、及其工程师、顾问、雇员、代理人为联合投保人。保险单应包含保险人放弃对业主及其工程师、顾问、雇员及代理人的代位权之条款。 3.承包商应保持上述保单的完全有效性,直到本合同对其规定的义务解除为止。业主有权随时索取保单、背书、续保和保险费收据的复印件。如果承包商未能全面投保,业主应有权代表承包商办理上述保险,支付所有相关保费,并从支付给承包商的款项中扣除有关费用。第十一条 完工 1.一俟工厂的全部建设和安装工程完工,承包商应通知业主,并根据附录_________的规定进行机械安装完成测试工作,直至业主满意。 2.测试圆满结束后,业主应签发一份完工证明书。在完工证明书签发之前,不得给工厂进料。 3.如果在建造和安装中出现不影响完成安装的小缺陷,或者在测试中测出不影响工厂开工的缺陷,业主应签发完工证明书,而承包商则有义务尽快修复这些不足之处。第十二条 最后验收 1.完工证明书颁发之后,承包商应提前_________天将工厂性能测试的时间通知业主。 2.为使测试准时开始,业主应按附录_________中的要求提供原料和其他设备,而承包商应按通知的时间开始性能测试。 (科教范文网 fw.nseac.com编辑发布) 3.性能测试将按附示_________的规定进行。测试成功后,业主应签发一份最后验收证明书,证明工厂已从证书签发日起移交业主。 4.如果工厂未能通过性能测试,承包商在进行他认为必要的调整之后,应在业主在场的情况下重新进行测试,时间由双方商定,条件照旧。 5.在最后验收合格证书签发之前,工厂不得投入商业性运转。如工厂未能通过性能测试,业主仍可酌情颁发最后验收合格证书,条件是承包商必须尽快纠正工厂存在的问题。第十三条 违约赔偿金 1.如果由于承包商的原因导致性能测试的再次失败,而双方并无继续重新测试的协议,则对最后一次测试的结果进行评估。承包商将根据附录_________的规定向业主支付违约赔偿费,费率不超过合同价格的_________%。 2.如果承包商因自身的原因未能在合同生效后的_________个月内获得整个工厂的最后验收合格证书,承包商须根据附录_________的规定向业主每月支付相当于合同价格_________%的拖延赔偿费,但最多不超过合同价格的_________%。 3.承包商应根据附录_________规定的格式开立一份以业主为受益人、金额为合同价格_________%的保证书,作为其履行本条款项下义务的保证。第十四条 保修 1.承包商保证,在最后验收合格证书签发日起_________个月内或本合同生效日期_________个月内(以先到日期为准),所提供的工厂无设计、材料和工艺上的缺陷。 2.发现问题后,如果承包商的代表在现场工作,业主应在_________天内按本条款以书面形式向承包商提出全部要求;如果承包商的代表不在现场,业主应在_________天内以航空邮件将确证材料发往承包商总公司。承包商应更换或修理所有有缺陷的零部件。为此,应允许承包商随时自由出入工地,检查缺损部件,使其能履行本保修条款。如果承包商因某种特殊情况未能在适当期限内进行双方同意的补救工作,业主有权自行修复,但费用由承包商负担。 (转载自http://zw.NSEAC.com科教作文网) 3.本保修的先决条件是,业主须按承包商的指示和具体规定的性能参数对工厂进行装备、操作和维护。如果业主未经承包商同意试图自行修正,则本保修条款无效。 4.本保修条款不包括因自然损坏的物件,也不包括使用寿命不到_________个月的消耗品或类似物件。 5.如果承包商遵照上更换任何设备、材料或工艺,则本保修条款的规定也适用于经修理或更换的设备、材料或工艺,期限为从修理或更换完成之日起1年。第十五条 专利权和专利使用费 1.承包商应全力保护业主在使用其提供的工帮时免遭因侵犯第三方的专利、设计或版权而面临的诉讼、索赔、要求和各种费用。 2.如果承包商提供的工程设计、工厂设备的制造和供应以及在工程建造中实施的工作或使用的方法涉及了第三方的专利,他也应向终第三方支付按许可证或许可知要款规定应支付的所有费用、专利使用费和其他款项。但是,如果业主在经营或使用该厂或其中任何部分时涉及了第三方的专利,他应向第三方支付按许可证或许可条款规定应支付的所有费用、专利使用费和其他款项。第十六条暂停 1.业主有权随时向承包商发出书面通知,指示其暂停工程的任何部分或整个工程,如果暂停期超过_________天,则按合同第_________条规定作终止合同处理。 2.如果业主未能按照本合同在规定日期_________天内向承包商支付任何款项,或者如果承包商因业主在履行合同上的失误而被中断或拖延了工程的进行,承包商有权暂停执行本合同。 3.如果工程按本条款规定暂停,承包商有权收取附加费用,以补偿由于此类暂停、中断和拖延,以及本合同的合理延期执行所造成的成本增加。 大学排名 第十七条 合同终止 1.按照第_________第规定,如果暂停时间持续超过_________天,任何一方都有权通知另一方立即终止本合同。 2.业主可以随时书面命令承包商停工,承包商在收到终止命令后应停止工地上所有的工作,但工程师出于保护、安全目的,或整理已建的或正在安装的工程,这类工作仍可继续。承包商在收到终止命令后,也应立即停止所有正在工地外进行的履行合同的工作。 3.根据本条款和第_________条规定,合同终止后,承包商有权收取下列费用: a.与所完成的工程和劳务相应的那部分合同价格; b.与已完成但未移交的工厂相应的那部分合同价格。第十八条 不可抗力 1.如果任何一方因不可抗力而款能履行或推迟履行其义务,则不对另一方负责,也不应视作违反合同。 2.不可抗力指业主或承包商无法控制的情况,使当事人未能按本合同履行其义务,或者不得不延迟履行其义务。下列情况均被视作不可抗力: a.战争、敌对事件、外敌行动、入侵、类似战争的军事行动(不管是事宣战)、内战; b.士兵哗变、民众暴乱、军事叛乱、起义、造反、革命、篡权、或者任何个人代表某个组织或与某个组织有联系、旨在以暴力推翻合法或现存政府、或以恐怖主义或暴力对政府施加影响的行为; c.地震、洪水、火灾或其他自然灾害; d.所有港口、机场、船运或其他公共交通工具的使用均遭拒绝; e.工人罢工、工厂停工、或其他的劳工联合行动,影响了承包商和分包商履行其义务; f.当事人无法控制、从而使其不能履行义务的其他任何意外情况。 (科教作文网http://zw.ΝsΕAc.Com编辑整理) 3.如果本合同任何一方因不可抗力不能或延迟履行本合同规定的任何义务,他可将不可抗力和由此造成的延迟或妨碍情况通知另一方。发出通知的一方允许根据具体情况及妨碍或延迟持续的时间免于履行或推迟履行合同。 4.根据本第款第3分条规定,如果任何一方免于履行或推迟履行其义务的时间持续了_________个月,那么任何一方都可随时向另一方发出书面通知,终止本合同。第十九条 转让及分包 1.承包商有权按其惯例分包本合同或本合同的任何部分,而不解除承包商履行本合同的任何义务。 2.事先未经另一方书面同意,任何一方都不得将本合同或其中的权利、义务,或合同的任何部分转让或让与第三方,除非公司合并或改组。如出现此种情况,任何一方都不应毫无理由地予以拒绝。第二十条 宣传 承包商在作与本合同相关的宣传材料的散发或公开宣布前,应征得业主的同意。第二十一条 合同生效日 1.本合同生效日为双方签字后,业主获得当事人双方各自有关当局的所有必要批文之日。 2.如果本合同自签字之日起_________天内仍不能生效,合同即被视作无效,除非双方另有商定。第二十二条 法律和规定 1.承包商应在与履行本合同有关的所有事务中遵守所有适用的法律、法规和命令。 2.本合同的解释、效力和履行,应完全以_________国的法律为准。第二十三条 完整合同 1.本合同是与约双方之间的完整协议,它取代了以前所有与本合同事项有关的洽谈、说明及口头或书面协议。 2.对本合同的任何修改或补充,须经业主和承包商双方的书面同意。第二十四条 合同语言(转载自科教范文网http://fw.nseac.com)
本合同以中文和英语起草,并以英文本为准,对方双均有约束力。第二十五条 通知 1.按本合同发出的每个通知、同意、指示、命令或决定,应以书面形式发送。发送方式有:向对方有关官员当面递交,或预付邮资航空传递,或通过电报、电传,或先发电报后信件确认。通讯地址如下: 业主:_________; 承包商:_________。 2.如果通知、同意、请求和其他文件发往某个海外目的地,在邮寄日后第_________天应视作已经送交;如果发往国内目的地,在邮寄日后第_________天视作已经送交。用电报、电传发出的通知、同意或请求应视作当天送达。 3.按本条款发送的所有通知、同意、批示或决定,应由有关方正式授权的代表签字。任何一方任何时候如欲变动收件地址,应以书面形式通知对方。承包商(盖章):_________ 业主(盖章):_________ 代表人(签字):_________ 代表人(签字):_________ _________年____月____日 _________年____月____日 签订地点:_________ 签订地点:_________附件
article 1- definitions "the owner" shall mean_________ "the contractor" shall mean_________ "the plant" shall mean all or any part of the machinery, equipment and materials forming the permanent installation as specified in appendix(_________). "the site" shall mean all the land where the plant is to be constructed in accordance with this contract. 本文来自中国科教评价网 "the works" shall mean the works to be done by the contractor under this contract. "the contract price" shall mean the total sum payable to the contractor by the owner for the works. article 2- contractor"s responsibilities 1. the contractor shall design, engineer, and construct the plant at the site. 2. the contractor shall provide all equipment, materials, tools, facilities, labour and services necessary for the successful construction of the plant except those items and facilities to be supplied by the owner under article (_________). 3. the contractor shall perform the works in accordance with the schedule in appendix (_________). 4. the contractor shall provide the owner"s personnel with training of operation and maintenance of the plant in accordance with appendix (_________). 5. the contractor shall supply the owner with the spare parts specified in appendix (_________). 6. the contractor shall supply the owner with the maintenance equipment specified in appendix (_________). article 3- owner"s responsibilities 1. the owner shall make available the site and grant the contractor free and uninterrupted access thereto throughout the duration of this contract. 2. the owner shall provide those items and facilities specified in appendix (_________) at the time therein established. 3. the owner will obtain from the relevant authorities those licenses and permits necessary to construct and operate the plant on the site including work permit for the contractor"s employees. 4. the owner shall pay the contractor for the works performed the contract price set out in article (_________). article 4- contract price 1. within (_________) days after the effective date of this contract, the owner shall pay the contractor as full and complete compensation for accomplishing the works and assuming all obligations under this contract the contract price in the amount of _________. (科教范文网http://fw.ΝsΕΑc.com编辑) 2. the contract price is not subject to escalation, and the cost of executing the works shall be the risk of the contractor who shall be deemed to have obtained all information and taken into account all circumstances which may affect the cost in agreeing the contract price. article 5- drawings 1. the contractor shall submit to the owner for approval and review within the time specified in appendix (_________) such drawings as may be required for construction of the plant under this contract. within one month after receiving such drawings the owner shall review and approve or disapprove the drawing. 2. the contractor shall be responsible for any defects, errors or omissions in the above drawings unless such defects, errors or omissions are caused by inaccurate information furnished in writing to the contractor by the owner. 3. all drawings and technical documentation delivered by the owner or the contractor to the other party shall be treated as confidential by the receiving party unless agreed otherwise, and shall not be used by that party for purposes other than those connected with this contract. article 6- inspection 1. the contractor shall perform all inspection and testing of the plant required by law and normal engineering practice. 2. the owner shall be entitled at all reasonable times and at its own cost to inspect, examine and test the materials and workmanship of the plant under construction. such inspection, examination or testing if made shall not release the contractor from any obligation under the contract. 3. the completed plant shall be inspected, examined and tested by the owner, and the contractor shall give the owner reasonable notice in writing of the date on which the plant will be ready for testing. 4. the contractor shall provide such assistance, labour, materials, electricity , fuels, apparatus, stores and instruments as may be required and as may be reasonably demanded to carry out such tests by the owner properly and efficiently.本文来自中国科教评价网
5. when the plant shall have passed the above tests, the owner shall furnish the contractor with a certificate in writing to that effect. no plant shall be delivered until any faults discovered during inspection are satisfactorily rectified. article 7- inspection 1. the contractor shall provide at the site to the reasonable satisfaction of the owner all materials, labour, equipment, services and facilities that may be necessary for the proper execution and completion of the works. 2. without prejudice to the generality of the above, the contractor shall provide, as may be necessary, the following: (1)construction equipment. (2)means of transport within the site including temporary roadways. (3)fencing, lighting and guarding and all other materials and services necessary for the safety and security of persons and property. (4)temporary stores, offices and other buildings or structures for materials and persons engaged in the words, including persons employed by the owner. (5)telephones, fire-fighting equipment and first-aid equipment until the whole works have been taken over. (6)sanitary and canteen facilities for the use of persons engaged in the works. 3. the contractor shall observe all safety and other regulations imposed on the site by local laws. 4. the contractor shall at all times keep the owner"s property and the adjoining premises, driveways and streets free of construction materials and rubbish caused by the works, and at the completion of the works shall remove all remaining materials from and about the premises and shall leave the site and plant safe, clean and ready for use. article 8- inspection 1. the contractor will supply at his own cost food, transprot and all necessary facilities for all his own personnel.(科教作文网http://zw.ΝsΕac.cOM编辑)
2. on signing the contract, the contractor shall appoint a project manager who will represent the contractor at all times be present at the site during working hours. all communications issued by the owner to the project manager shall be binding as if given to the contractor. 3. the owner may request the removal and replacement of any person employed by the contractor on the site if such person is in the owner"s opinion guilty of misconduct, incompetence or negligence. article 9- inspection 1. the contractor shall be responsible for all losses of or damage to the plant before final acceptance, and shall make good al such loss or damage at the cost of the contractor and to the reasonable satisfaction of the owner provided, however, in the case of loss or damage to the plant arising from or occasioned by causes for which the contractor is mot responsible under the contract, the same shall be made good by the contractor but at the cost of the owner, if the owner so directs. 2. the contractor shall indemnify the owner in respect of all damage and injury occurring before the issue of the final acceptance certificate to any property and person and against all actions, suits, claims, demands, charges and expenses arising in connection therewith which shall be occasioned by the negligence of the contractor or any of his sub-contractors or by defective design, materials or workmanship but not otherwise. 3. in the event of any claim being made or actions pought against the owner arising out of any matter in respect of which the contractor is or may be liable under this article, the owner shall promptly notify the contractor in writing thereof and the contractor shall at his own expense take over and conduct in the name of the owner all negotiations for the settlement of the same and any litigation that may arise therefrom. the owner shall at the request of the contractor afford all such information and assistance as the contractor may reasonably require for the purpose of dealing with any such claim or action. (科教作文网 zw.nseac.com整理) article 10- inspection 1. without limiting the contractor"s liabilities the contractor will at his own expense take out the following insurance: (1)transportation insurance on the machine and equipment from its delivery ex works to arrival at the site. (2)workers compensation insurance for all contractor"s and subcontractor"s employees engaged or similar statutory social insurance in accordance with the applicable laws and regulations. (3)product liability insurance against damage to property or injury to persons until the end of the maintenance period in the sum not less that (amount) us dollars per occurrence. (4)comprehensive automobile liability insurance in respect of all vehicles used by the contractor or his sub-contractor in connection with his contract. 2. the aforesaid policies of insurance will be taken out in the names of the contractor and its sub-contractors, the owner, their engineer, consultant and employees and agents as the joint insured and the policies shall contain a waiver of insurer"s rights of supogation against the owner, its engineer, consultant and employees and agents. 3. the contractor shall maintain the aforesaid policies in full force and effect until the discharge of his obligations under this contract, and the owner shall have the right to demand from time to time copies of the policies, endorsements and renewals and receipts for payment of insurance premiums. if the contractor fails to maintain any of these policies in full force and effect, the owner shall have the right to rake out such policies and pay all relative premiums on behalf of the contractor and to deduct the relevant costs from and sums owing to the contractor. article 11- inspection 1. on completion of all construction and erection work of the plant, the contractor shall inform the owner and shall carry out mechanical erection completion tests specified in appendix (_________) to the satisfaction of the owner. (科教范文网 lw.nseaC.Com编辑发布) 2. on satisfactory completion of such tests the owner will issue a certificate of completion of erection of the plant. no feedstock shall be fed into the plant until a certificate of completion of erection has been issued. 3. in the event of minor deficiencies in the construction and erection work which do not prevent erection completion and/or in the event of defects revealed by the tests which do not prevent the start-up of the plant, the owner shall issue a certificate of completion of erection and the contractor shall be obliged to rectify the deficiencies as quickly as possible thereafter. article 12- inspection 1. following the issue of the certificates of completion of erection the contractor shall give the owner (_________) days notice of the date when he will be ready to carry out performance tests of the plant. 2. the owner shall provide the feedstock and other facilities required in appendix (_________) to enable the tests to commence on time and the contractor shall begin the performance tests at the time so notified. 3. the performance tests will be carried out in acceptance with the provisions of appendix (_________) and on their successful completion, the owner shall issue a final acceptance certificate stating that the plant has been taken over by the owner as from the date thereof. 4. if the plant fails to pass its performance test, then the contractor, after making such adjustments as he considers necessary, shall repeat such tests in the presence of the owner at a time to be agreed upon under the same terms and conditions as the original tests. 5. the plant shall not be commercially operated before the issue of the final acceptance certificate. notwithstanding the failure of the plant to pass its performance tests, the owner may at his discretion issue a final acceptance certificate subject to the contractor remedying the plant defects as soon as possible. (转载自http://zw.nseac.coM科教作文网) article 13- inspection 1. in the event of any repeat of a performance test failing for reasons imputable to the contractor, and there being no mutual agreement to continue re-testing, the results of the final test will be measured and the contractor will be liable to pay to the owner liquidated damages on the scale set out in appendix(_________) up to a maximum of (_________)% of the contract price. 2. if the contractor is unable for reasons within his control to obtain a final acceptance certificate for the whole plant by(_________) months from the effective date of this contract, he shall be liable to pay to the owner for each month"s delay liquidated damages of(_________)% of the contract price up to a maximum of (_________)% of the contract price in accordance with appendix(_________). 3. the contractor shall establish, in favour of the owner, a guarantee for(_________)% of the contract price in the form set out in appendix(_________) in support of his obligations under this article. article 14- inspection 1. the contractor warrants, for a period of (_________) months from the date of issue of the final acceptance certificate or(_________) months from the effective date of this contract whichever is the earlier, the supplied plant against faulty design, material and workmanship. 2. the owner shall inform the contractor in writing of all claims arising under this provision within(_________)days of the detection of fault, if the contractor"s representative is on site or within(_________)days if not, to the contractor"s head office by telex r recorded air mail delivery with supporting data. the contractor shall have the option to replace or repair all parts proved deficient. for this purpose the contractor shall have the option to replace or repair all parts proved deficient. for this purpose the contractor shall have an access to the site to inspect the faulty parts at any time and to enable him to comply with the terms of this guarantee. should the contractor fail to carry out agreed remedial work within any period of time reasonable in the particular circumstance, the owner shall have the right to do this work at the contractor"s expense. (科教范文网 lw.AsEac.com编辑整理) 3. this warranty is given subject to the owner storing, operating and maintaining the plant in accordance with the contractor"s instructions and specified operating parameters and may be nullified in the event of the owner attempting rectification work without the contractor"s agreement. 4. this warranty does not include items which fail due to natural wear and tear, or consumables or similar items whose natural life is (_________) months or less. 5. if pursuant to the above warranty the contractor repairs or replaces any equipment, materials or workmanship, the provisions of this article shall them apply to said repaired or replaced equipment, materials or workmanship for a period of one year from the date such repairs or replacements are completed. article 15- patent rights and royalties 1. the contractor shall fully indemnify the owner against all actions, claims, demands, costs, charges and expenses arising from or incurred by reason of any infringement of patents, design or copyright of third parties by the use of the plant supplied by the contractor. 2. the contractor shall also be responsible for the payment to third parties of all fees, royalties and other charges, if and, that may be payable under the terms of any license or permission in respect of any design of the works provided by the contractor, the manufactured and supply of the plant and any work done or method employed in the construction of the works. however, the owner shall be responsible for the payment to third parties of all fees, royalties and other charges, if any, that may be payable under the terms of any license or permission in respect of the operation or use of the plant or any part thereof. article 16- suspension 1. the owner shall have the right to instruct the contractor to suspend any part or the whole of the works at any time upon giving written notice to the contractor provided that any period of suspension exceeding (_________) days shall be treated as termination under article (_________)。 (科教作文网http://zw.ΝsΕAc.com发布) 2. if the owner fails to make any payment to the contractor under this contract within (_________) days of the due date, or if the contractor is otherwise interrupted or delayed in the performance of the works due to the owner"s contractual default, the contractor shall be entitled to suspend performance of this contract. 3. in the event of suspension of the works in accordance with this article the contractor shall be entitled to receive such reasonable additional payment as may be necessary to compensate for the additional costs arising out of such suspension, interruption or delay and such reasonable extension of time for performance of contract. article 17- termination 1. in the event of suspension in accordance with article (_________) lasting for a period of more than (_________) days either party shall have the right to give notice to the other party of the immediate termination of this contract. 2. the owner may at any time by written order to the contractor order the contractor to cease further execution of the works, and the contractor shall upon receipt of a termination order, cease all further work on the site other than such work thereon as the engineer may instruct for the purpose of protecting, making safe or tidying up such parts of the works as may already have been executed or be in course of erection. the contractor shall, as soon as practicable after receipt of the termination order, also cease all such further work as is being done off the site in the performance of this contract. 3. upon termination of this contract under this article and under article (_________), the contractor shall be entitled to be paid: (1)that part of the contract price which is proportionate to engineering and services carried out, and (2)that part of the contract price which is proportionate to the plant completed but not delivered.内容来自www.nseac.com
article 18- force majeure 1. no party to this contract shall be liable to the other party for any failure of or delay in performance of its obligations hereof nor be deemed to be in peach of this contract, if such failure or delay has arisen from "force majeure." 2. "force majeure" means circumstances and conditions beyond the control of either parties, that would render it impossible for either the owner or the contractor to fulfill their obligations under this contract, or delay such fulfillment. any of the following matters are considered "force majeure." (1)war, hostilities, act of foreign enemy, invasion, warlike opera-tions (whether war to be declared or not) or civil war; (2)mutiny, civil commotion assuming the proportions of or amounting to a popular rising, military rising, insurrection, rebellion, revolution, military or usurped power, or any act of any person acting on behalf of or in connection with any organization with activities directed towards the overthrow by force of the government de jure or de facto, or to the influencing of it by terrorism or violence; (3)earthquake, flood, fire or other natural physical disaster; (4)denial of the use of all ports, airports, shipping services or other means of public transport; (5)trike or lock out or other industrial concerted action by workers, affecting the fulfillment of contractor"s and subcontractors" obligations; (6)and other unforeseen circumstances beyond the control of the parties so affected rendering the fulfillment of their obligations impossible. 3. if either party to this contract is prevented or delayed from or in performing any of his obligations under this contract by force majeure, then he may notify the other party of the circumstances constituting the force majeure and of the obligation performance of which is thereby delayed or prevented and the party giving the notice shall thereupon be excused from the performance or punctual performance, as the case may be, of such obligation for so long as the circumstances of prevention or delay may continue. (科教范文网http://fw.nseac.com) 4. if by virtue of the preceding sub-clause dither party shall be excused from the performance or punctual performance of any obligation for a continuous period of (_________) months, then either party may at any time thereafter terminate this contract by giving a written notice to the other party. article 19- assignment and sub-contractors 1. the contractor shall have the right to sub-contract this contract or any part thereof in accordance with his usual practice without relieving the contractor of the obligations of performing this contract. 2. neither party shall without the previous consent in writing of the other party assign or any part thereof to any third party, except in the case of a company amalgamation or reconstruction, provided that such consent shall not be unreasonably withheld. article 20- publicity the contractor shall obtain the owner"s approval prior to making any publicity releases or public announcements relating to this contract. article 21- effective date of the contract 1. the effective date of this contract shall be the date after its execution when all the necessary approvals of the respective authorities have been obtained by the owner. 2. if the contract does not become effective within(_________) days from the date of execution, it will be deemed void unless otherwise agreed between the parties. article 22- law and regulations 1. the contractor shall in all matters relating to the performance of this contract conform with all applicable laws, regulations and orders of central or local authorities. 2. the construction, validity and performance of this contract shall be governed in all respects in accordance with the laws of _________ article 23- entire contract 1. this contract constitutes the entire agreement between the parties hereto and supersedes all prior negotiations, representations or agreements whether oral or in writing relative to the subject matter of this contract. 本文来自中国科教评价网 2. this contract shall be altered or supplemented only by mutual consent in writing between the owner and the contractor. article 24- language of the contract this contract was drafted in english language and the english text of this contract shall be valid and binding upon the parties hereto. article 25- notices 1. every notice, consent, instruction, order or decision given under this contract shall be given or made in writing and either personally served on an officer of the party to whom it is given or airmailed post-prepaid or sent by telegram, telex or cable subsequently confirmed by letter, addressed as follows: to:the owner (address) _________to: the contractor (address) _________. 2. notices, consents, requests and other documents shall be deemed delivered or given, if mailed to an overseas destination, on the (_________) th day after the date of mailing and, if mailed to a domestic destination, the (_________) th day after the date of mailing. notices, consents or requests sent by telegram, telex or cable shall be deemed delivered or given on the day they are despatched. 3. any notice, consent, instruction, or decision given under this article shall be signed on behalf of either party by any duly authorised representative of that party. either of the parties may change his address for receipt of notices, instructions or decisions and other documents at any time by giving notice thereof in writing to the other party.the owner (signature):_________ the contractor(signature):_________date:_________ date:_________相关热词搜索:建造 工厂 合同 劳动合同模板 工程承包合同书模板
- 范文大全
- 说说大全
- 学习资料
- 语录
- 生肖
- 解梦
- 十二星座
-
2022年4月主题党日活动记录范文15篇
2022年4月主题党日活动记录范文15篇2022年4月主题党日活动记录范文篇1一个崇尚阅读的民族,必然精神饱满、意气风发、活力四射。习近平总书记强调:“学习
【活动总结】 日期:2022-08-01
-
少先队的光荣历史故事 队前教育-光辉历程
2017-2018学年队前教育1光辉历程一、劳动童子团1924——1927二、三十年代年的中国是一个
【法律文书】 日期:2020-06-23
-
家乡赋|最美的家乡赋
家乡赋 孙传志 今安康市,白河双丰镇,吾之家乡也。三环沃土,山水环抱。其北依山,山系五岭,山
【调研报告】 日期:2020-04-01
-
党支部1-12月全年主题党日活动计划表
2022年党支部主题党日活动计划表序号活动时间活动方式活动内容12022年1月专题学习研讨集中观看2022年新年贺词,积极开展学习研讨交流。组织生活会组织党员认真对照党章...
【活动总结】 日期:2022-10-14
-
【人教版1-6年级数学上册知识点精编】1-6年级数学人教版教材
人教版二年级数学上册知识点汇总第一单元长度单位一、米和厘米1、测量物体的长度时,要用统一的标准去测量
【调研报告】 日期:2020-11-08
-
2022年2月份主题党日活动记录5篇
2022年2月份主题党日活动记录5篇2022年2月份主题党日活动记录篇1尊敬的党组织:在今年的开学初,本人积极参加教研室组织的教研活动,在学校教研员的指
【活动总结】 日期:2022-08-12
-
2023年平安校园建设方案13篇
平安校园建设方案“平安校园”创建工作,我们幼儿园全体教职员工一直把它当作头等大事来抓。领导高度重视,以“平安校园”创建活动为抓手,建立和规范校园安全工作机制
【规章制度】 日期:2023-11-02
-
医院最佳主题党日活动11篇
医院最佳主题党日活动11篇医院最佳主题党日活动篇1 医院最佳主题党日活动篇2为隆重纪念中国共产党成立100周年,进一步巩固党的群众路线教育实践活动成果,切实
【活动总结】 日期:2022-10-29
-
主题党日活动记录202210篇
主题党日活动记录202210篇主题党日活动记录2022篇12021年是中国共产党成立100周年,为广泛开展爱国主义宣传教育,铭记党的历史,讴歌党的光辉历程,
【活动总结】 日期:2022-08-02
-
南京大屠杀国家公祭日悼念文案句子11篇
南京大屠杀国家公祭日悼念文案精选句子1、惟有民魂是值得宝贵的,惟有他发扬起来,中国才有真进步。——鲁迅2、我爱我的祖国,爱我的人民,离开了它,离开了他们,我
【企划文案】 日期:2023-10-20
-
正式的晚宴邀请函 公司晚宴邀请函
尊敬的先生 女士: 我公司谨定于xxxx年xx月xx日xx:xx在xxxx店隆重举行xx市xx届xxxx晚宴(宴会地址:xx区xx路xxxx) 敬请届时光临!xxxxxx集团股份有限公司xxxx有限公司敬邀xxxx年xx月xx日
【简历资料】 日期:2019-08-03
-
一年级新学期目标简短_一年级学生新学期打算
新学期到了,我是一年级下册的小学生了。 上课的时候,我要认真学习,不做小动作,认真听讲。我要认真学习,天天向上,努力学习,耳朵要听老师讲课,眼睛要瞪得大大的看老...
【简历资料】 日期:2019-10-26
-
[信访复查复核制度作用探讨]信访复查复核有用吗
作为我国特有的一项制度,信访制度的出现并长期存在不是偶然的,虽然一些法学专家认为信访制度具有“人治”
【职场指南】 日期:2020-02-16
-
入少先队员改正的缺点有哪些_少先队申请书
敬爱的少先队组织:我们是共产主义接班人,继承革命先辈的光荣传统,爱祖国,爱人民,鲜艳的红领巾飘扬在前胸 我叫xx,是一年级(x)班的小学生。每当听到这首...
【简历资料】 日期:2019-07-28
-
[党员干部2019年主题教育个人问题检视清单及整改措施2篇] 党员干部
2019年主题教育问题检视清单及整改措施根据主题教育领导小组办公室《关于认真做好主题教育检视问题整改
【求职简历】 日期:2019-11-08
-
网络维护工作内容_(精华)国家开放大学电大专科《网络系统管理与维护》形考任务1答案
国家开放大学电大专科《网络系统管理与维护》形考任务1答案形考任务1理解上网行为管理软件的功能【实训目
【职场指南】 日期:2020-07-17
-
党委会与局长办公会的区别_局长办公会制度
为进一步加强xxx局工作的规范化、制度化建设,提高行政效能,规范议事程序,特制定本制度。一、会议形式1、局长办公会议由局长、副局长参加。由局长召集和主持。根据工作需要...
【求职简历】 日期:2019-07-30
-
学生会组织部部长竞选稿5篇
学生会组织部部长竞选稿以“三制”为统领推进农村党的建设中共**市委组织部近年来,**市认真落实中央、省和徐州市委的部署,积极适应发展要求,从加强领导体制、运
【求职简历】 日期:2023-11-06
-
如何凝心聚力谋发展【坚定信心谋发展凝心聚力促跨越】
当前,清河正处于在苏北实现赶超跨越基础上全面腾飞的战略机遇期,处于在全市率先实现全面小康基础上率先实
【简历资料】 日期:2020-03-17
-
《铁拳砸碎“黑警伞”》警示教育片观后感
影片深刻剖析了广西北海市公安局海西派出所原所长张枭杰蜕变堕落的轨迹。观看警示教育片后,做为一名党员教
【简历资料】 日期:2020-08-17
-
无疫村创建总结10篇
无疫村创建总结10篇无疫村创建总结篇1为了构建和谐医患关系,创建平安医院,我院采取了一系列行动,全面推进我院平安医院创建工作,现将活动总结如下。一、
【其他范文】 日期:2022-09-19
-
2022纪检干部脱贫攻坚专项巡视反馈整改民主生活会对照检查材料
下面是小编为大家整理的2022纪检干部脱贫攻坚专项巡视反馈整改民主生活会对照检查材料
【其他范文】 日期:2022-08-30
-
肾移植术后抗体介导排斥反应中不同亚型的巨噬细胞浸润分析
邓格,豆猛,宫惠琳,郑秉暄,石玉婷,卫田,丁晨光,郑瑾,丁小明,薛武军,田普训( 西安交通大学第一附
【其他范文】 日期:2023-01-15
-
2021林业局半年工作总结会讲话|2019年县林业局工作总结
2021林业局半年工作总结会讲话一、上半年工作概况。半年来,我局认真贯彻x全会精神,按照省、市林业工
【汇报体会】 日期:2020-12-05
-
2020秋季国家开放大学《中国近现代史纲要》试述外国资本帝国主义侵略中国到底给中国带来了什么?:
2020秋国家开放大学《中国近现代史纲要》终结性试题及答案论述题:历史不仅是最好的教科书,也是最好的
【礼仪】 日期:2020-12-18
-
【醒言】醒言是什么意思
【评语寄语】 日期:2020-03-30
-
市人民法院公正司法述职报告(精选文档)
一、主要工作情况*年以来,我院在市委的坚强领导和市人大及其常委会的有力监督下,坚持以习近平新时代中国特色社会主义思想为指导,深入贯彻落实党的十九届历次全会和中央、省...
【其他范文】 日期:2023-09-06
-
超分辨率OCR在计算机教学中的应用研究
郭卡安徽外国语学院在日常教学中,作业、板书等内容通常以手写形式呈现,为了方便教学记录及学习情况分析,
【其他范文】 日期:2023-02-22
-
2014年12月日语能力考试N1真题+参考答案
2014年12月N1级真题問題1の言葉の読み方として最もよいものを、1.2.3.4から一つ選びなさい
【导游词】 日期:2021-08-06
-
【X医院,2007~2009年党建工作规划】党建8十x工作制度
第PAGE页码页码页 共NUMPAGES总页数总页数页 X医院2007~2009年党建工作规划 x
【汇报体会】 日期:2020-07-21
-
军转座谈会交流发言4篇
军转座谈会交流发言4篇军转座谈会交流发言篇1大家好,我叫贺丽,2015届选调生,来自康定市委组织部,现在省委编办跟班学习。今天,非常荣幸向大家汇报我的学习收
【发言稿】 日期:2022-10-27
-
12岁生日小寿星发言4篇
12岁生日小寿星发言4篇12岁生日小寿星发言篇1各位来宾、各位朋友:大家好!今天,我们欢聚在这里,共同庆祝**十二周岁生日。首先,我代表**的父母以
【发言稿】 日期:2022-07-31
-
廉政大会总结发言稿7篇
廉政大会总结发言稿7篇廉政大会总结发言稿篇1各位领导,同志们:根据会议安排,我就党风廉政建设工作做表态发言,不妥之处,请批评指正。一、提高认识,切实
【发言稿】 日期:2022-10-30
-
我最敬佩的人开头_我敬佩的一个人作文20篇2020年
我敬佩的一个人作文20篇 我敬佩的一个人作文一): 我身边有很多值得我们敬佩的人,但我最敬佩的一
【发言稿】 日期:2020-11-10
-
纪委书记工作表态发言4篇
纪委书记工作表态发言4篇纪委书记工作表态发言篇1在镇党委政府正确领导下,在全村干部和群众的共同努力下,紧紧围绕建设社会主义新农村工作为重点,尽职尽责,与时俱
【发言稿】 日期:2022-09-30
-
党员教育培训总结交流发言12篇
党员教育培训总结交流发言12篇党员教育培训总结交流发言篇1根据市委组织部《关于开展我市〈20XX
【发言稿】 日期:2022-12-19
-
【企业疫情风险控制方案】 2020企业复工疫情方案
企业疫情风险控制方案2020新冠病毒肺炎疫情防控工作总结汇报3篇 关于新型冠状病毒感染的肺炎疫
【演讲稿】 日期:2020-02-27
-
[钻井队队长(副队长、指导员)岗位HSE应知应会试题(1863)]
钻井队队长(副队长、指导员)岗位HSE应知应会试题(判断题:771;单选题:626;多选题:466)
【贺词】 日期:2020-09-23
-
话剧《家》剧本 话剧剧本:爱的空间
找文章到更多原创-(http: www damishu cn)人物介绍:刘伟,男,32岁,某购物广
【演讲稿】 日期:2020-01-21
-
五言绝句大全500首古诗_五言绝句144首
五言绝句144首 五言绝句(一): 1《春夜喜雨》唐朝·杜甫 好雨知时节,当春乃发生。随风潜入
【祝福语】 日期:2021-03-13
-
2023年中国行政区划调整方案(设想优秀3篇
中国行政区划调整方案(设想优秀民政部第二次行政区划研讨会会议内容一、缩省的意义与原则1.意义1)利于减少中间层次中国行政区划层级之多为世界之最,既使管理成本
【周公解梦】 日期:2024-02-20
-
2023年和儿媳妇在一起幸福的句子3篇
和儿媳妇在一起幸福的句子1、假如人生不曾相遇,我还是那个我,偶尔做做梦,然后,开始日复一日的奔波,淹没在这喧嚣的城市里。我不会了解,这个世界还有这样的一个你
【格言】 日期:2023-11-10
-
XX老干局推进党建与业务深度融合发展工作情况调研报告:党建调研报告
XX老干局推进党建与业务深度融合 发展工作情况的调研报告 党建工作与业务工作融合发展始终是一个充满生
【成语大全】 日期:2020-08-28
-
中国共产党第三代中央领导集体的卓越贡献
中国共产党第三代中央领导集体的卓越贡献 --------------继往开来铸就辉煌 【摘要】改
【成语大全】 日期:2020-03-20
-
信息技术2.0能力点 [全国中小学教师信息技术应用能力提升工程试题题库及参考答案「精编」]
全国中小学教师信息技术应用能力提升工程试题题库及答案(复习资料)一、判断题题库(A为正确,B为错误)
【格言】 日期:2020-11-17
-
党建工作运行机制内容有哪些_构建基层党建工作运行机制探讨
党的基层组织是党在社会基层组织中的战斗堡垒,是党的全部工作和战斗力的基础。加强和改进县级以下各类党的
【经典阅读】 日期:2020-01-22
-
电大现代教育原理_最新国家开放大学电大《现代教育原理》形考任务2试题及答案
最新国家开放大学电大《现代教育原理》形考任务2试题及答案形考任务二一、多项选择题(共17道试题,共3
【成语大全】 日期:2020-07-20
-
集合推理_七,推理与集合
七推理与集合1 期中考试数学成绩出来了,三个好朋友分别考了88分,92分,95分。他们分别考了多少分
【名人名言】 日期:2020-12-18
-
基层党务工作基本内容_党建基本工作有哪些
党建基本工作有哪些(一) 基层党建工作包括哪些内容 选择了大学生村官这条路,你就与农村基层党
【名人名言】 日期:2020-08-06
-
【2020-2021学年高一英语外研版(2019)选择性必修第一册Unit3Faster,higher,strongerSectionⅠ导学讲义】
Unit3 Faster,higher,stronger背景导学MichaelJordan—Head
【歇后语】 日期:2021-04-19
-
关于三农工作重要论述心得体会3篇
关于三农工作重要论述心得体会3篇关于三农工作重要论述心得体会篇1习近平总书记指出:“建设现代化国家离不开农业农村现代化,要继续巩固脱贫攻坚成果,扎实推进乡村
【学习心得体会】 日期:2022-10-29
-
【福生庄隧道坍塌处理方案】 福生庄隧道在哪里
(呼和浩特铁路局大包电气化改造工程指挥部,内蒙古呼和浩特010050)摘要:文章介绍了福生庄隧道
【学习心得体会】 日期:2020-03-05
-
五个一百工程阅读心得体会13篇
五个一百工程阅读心得体会13篇五个一百工程阅读心得体会篇1凡益之道,与时偕行。在全国网络安全和信
【学习心得体会】 日期:2022-12-07
-
城管系统警示教育心得体会9篇
城管系统警示教育心得体会9篇城管系统警示教育心得体会篇1各党支部要召开多种形式的庆七一座谈会,组织广大党员进行座谈,回顾党的光辉历程,畅谈党的丰功伟绩,
【学习心得体会】 日期:2022-10-09
-
发展对象培训主要内容10篇
发展对象培训主要内容10篇发展对象培训主要内容篇1怀着无比激动的心情,我有幸参加了__新区区委党校20__年第四期(区级机关)党员发展对象培训班。这次的学习
【培训心得体会】 日期:2022-09-24
-
凝聚三种力量发展全过程人民民主心得体会12篇
凝聚三种力量发展全过程人民民主心得体会12篇凝聚三种力量发展全过程人民民主心得体会篇1新民主主义革命是指在帝国主义和无产阶级革命时代,殖民地半殖民地国家中的
【学习心得体会】 日期:2022-08-31
-
2022年全国检察长会议心得7篇
2022年全国检察长会议心得7篇2022年全国检察长会议心得篇1眼睛是心灵上的窗户,我们通过眼睛才能看到世间万物,才能看到眼前这美好的一切。拥有一双明亮的眼
【学习心得体会】 日期:2022-10-31
-
在街道深化作风建设推动高质量发展走在前列动员会上讲话
在2023年街道深化作风建设推动高质量发展走在前列动员会上的讲话同志们:今天我们召开“街道深化作风建设推动高质量发展走在前列动员会”,这次会议是街道三季度召开的第一场...
【军训心得体会】 日期:2024-03-17
-
全面从严治党的心得体会800字7篇
全面从严治党的心得体会800字7篇全面从严治党的心得体会800字篇1中国特色社会主义是我们党领导
【学习心得体会】 日期:2022-12-14
-
2月教师党员个人思想汇报5篇
2月教师党员个人思想汇报敬爱的党组织:最近这一个月的时间对于我来说是极不平凡的,在这段时间里我认真学习了文化部网上党校的相关内容,经过长达40小时的
【教师心得体会】 日期:2023-10-15
-
2024年主题教育民主生活会批评与自我批评意见(38条)(范文推荐)
2023年主题教育民主生活会六个方面个人检视、相互批评意见:1 理论学习系统性不强。学习习近平新时代中国特色社会主义思想不深不透,泛泛而学的时候多,深学细照的时候少,特...
【邓小平理论】 日期:2024-03-19
-
2024年交流发言:强化思想理论武装,增强奋进力量(完整)
习近平总书记指出:“一个民族要走在时代前列,就一刻不能没有理论思维,一刻不能没有思想指引。”党的十八大以来,伴随着新时代中国特色社会主义思想在实践中形成发展的历程...
【三个代表】 日期:2024-03-19
-
2024年度镇年度县乡人大代表述职评议活动总结
xx镇20xx年县乡人大代表述职评议活动总结为响应县级人大常委会关于开展县乡两级人大代表述职评议活动,进一步激发代表履职活力,加强代表与人民群众的联系,提高依法履职水平...
【马克思主义】 日期:2024-03-19
-
“千万工程”经验学习体会(研讨材料)
“千万工程”是总书记在浙江工作时亲自谋划、亲自部署、亲自推动的一项重大决策,也是习近平新时代中国特色社会主义思想在之江大地的生动实践。20年来,“千万工程”先后经历...
【三个代表】 日期:2024-03-19
-
2024年在市政协机关工作总结会议上讲话
同志们:刚才,XX同志对市政协机关20XX年工作进行了很好的总结,很精炼,很到位,可以感受到去年机关工作确实可圈可点。XX同志宣读了表彰决定,机关优秀人员代表、先进集体代...
【邓小平理论】 日期:2024-03-18
-
在全区防汛防涝动员暨河长制工作推进会上讲话提纲【完整版】
区长,各位领导,同志们:汛期已经来临,我区城区防涝工作面临强大考验,形势不容乐观。年初,区城区防涝排渍指挥部已经召开专题调度会,修订完善应急预案,建立网格化管理机...
【马克思主义】 日期:2024-03-18
-
2024年镇作风整治工作实施方案(完整文档)
XX镇作风整治工作实施方案为深入贯彻落实党的二十大精神及省市区委深化作风建设的最新要求,突出重点推进干部效能提升,坚持不懈推动作风整治工作纵深发展,根据《关于印发《2...
【毛泽东思想】 日期:2024-03-18
-
2024市优化法治化营商环境规范涉企行政执法实施方案【优秀范文】
xx市优化法治化营商环境规范涉企行政执法实施方案为持续优化法治化营商环境,激发市场主体活力和社会创造力,规范行政执法行为,创新行政执法方式,提升行政执法质效,着力解...
【毛泽东思想】 日期:2024-03-18
-
2024年度关于开展新一轮思想状况摸底排查工作通知(完整)
关于开展新一轮思想状况摸底排查工作的通知为深入贯彻落实关于各地开展干部职工思想状况大摸底大排查情况上的批示要求和改革教育第二次调度会议精神,有针对性做好队伍教育管...
【三个代表】 日期:2024-03-18
-
2024年公路养护中心主任典型事迹材料(完整文档)
“中心的工作就是心中的事业”——公路养护中心主任典型事迹材料**,男,1976年6月出生,1993年参加工作,2000年4月调入**区交通运输局工作,大学本科学历,中共党员,现任**...
【马克思主义】 日期:2024-03-17